Clean Energy Regulator is as in http://ret.cleanenergyregulator.gov.au/
System means solar power system.
Installation address is the premises where the system is to be installed.
AjAgri PTY Ltd ABN 21 152 343 407
STCs means the Small-Scale Technology Certificates.
2. Customer Declarations:
2.1. You are over the legal age of 18 years.
2.2. You are one of the registered owners of the property at the installation address and your name is on the title deed of the installation address.
2.3. You are never received or have never been approved for any rebate, financial assistance solar credit or small-scale technology certificate (STCs) for small generation solar power system at the installation address.
3. Payment & STC’s:
3.1. AS must have the final payment prior to OR on the day of the installation by Credit Card or Cheque. If you prefer Electronic Fund Transfer (EFT), the transaction must be completed 48 Hours prior to installation and you must provide us with written proof of the transfer. The customer must provide Credit Card details/cheque/EFT Receipt to Installer prior to the Installation. Installation will not be carried out unless we have received payment.
3.2. You are agreeing to pay AS the STC’s as part payment for your system. The STC’s will be paid directly to AS or an AS Agent. If the office of Clean Energy Regulator (http://ret.cleanenergyregulator.gov.au/) determines you are not eligible to receive STC’s, and therefore AS is unable to receive the STC’s as part payment, you will be liable to pay AS the value of the STC’s, as determined by market rates.
3.3. If you are not eligible for STC’s, or if you wish to claim the STC’s incentive yourself, the complete payment (including trading costs of STC’s) of the system is due before installation.
3.4. You acknowledge that if you breach any conditions of the STC’s incentive regulations, you may be financially liable to the Office of Clean Energy Regulator (http://ret.cleanenergyregulator.gov.au/). If you commit any breach of the incentive regulation, you acknowledge that AS will not be liable to you.
3.5. AS or An AS Agent will arrange for the complete documentation and processing of the sale of STC’s. You acknowledge that price of STC’s is governed by market movements and the REC guidelines. If the market price falls below a certain price, AS may decide to delay the installation until the price rises to a higher level. AS may also refuse to carry out installation and refund you complete deposit. If the market price follow below the certain price, as determined by AS at its absolute discretion.
3.6. If you fail to pay any amount that is due and payable under this agreement, AS will be entitled to charge interest on the unpaid amount at 2.5% plus administration fee of $220. You will also have to pay AS any costs associated with the recovery of such unpaid amounts.
3.7. Title and ownership of the solar system will vet in you upon AS receiving complete payment from you for the cost of the solar system.
3.8. Failure to pay the complete amount may result in AS taking legal action against you and it will void all warranties.
4. Authority of access to property:
4.1. You authorise AS and its contractors, employees and installers. Full access to the property at all reasonable times to carry out all work associated with the installation of your solar system including site Inspections, the signing of required paperwork, the delivery and installation of the PV Solar system, and connection to the grid.
4.2. Your co-operation is required to enable site inspections/installation to occur at the earliest possible time that is convenient to AS.
5. Liabilities and Risk:
5.1. The ownership and insurance risk of the PV solar system passes to you upon installation and AS receiving full payment for the solar system. It is your responsibility to ensure that your property insurance adequately covers the cost of your PV solar system.
5.2. You acknowledge AS accepts no liability or responsibility for your STC’s incentive as administered by the Office of Clean Energy Regulator (http://ret.cleanenergyregulator.gov.au/)
5.3. You acknowledge AS accepts no liability or responsibility for your STC’s Bonus, also known as the “feed in tariff incentive” as administered by the relevant State or Territory government.
5.4. AS accepts no responsibility for any damage or loss caused to your property by the installer that has not been caused by the installer’s negligence. All AS installers are subcontractors who are required by AS to have appropriate third-party damage insurance, under relevant state and territory laws. AS will work with you and the installer to rectify any damage caused to your property by the installer’s negligence.
5.5. You acknowledge that AS will not be responsible for any damage caused to old and brittle roofing tiles that may be cracked or damaged during installation.
5.6. AS accepts no responsibility for any additional costs associated if you need to obtain an upgrade of your existing meter box or the installation of a new gross/net meter. AS will not be liable for any unexpected cost that may arise in relation to the removal and handling of asbestos at your property in relation to the installation of the solar system.
6.1. AS quote does not include the costs of any wiring or any associated work required to connect your inverter to a meter box that is remotely located from the inverter. (i.e. where the meter box is not attached to the same structure as the inverter such as the house or the garage.) If the meter box is located remotely from the inverter location and such costs are not provided for in the
relevant AS quote, you will be required to arrange and pay for the performance of this electrical work separately from installation of the solar system.
6.2. Addition minimum charges may be applicable such as $200 to split the system in more than one row, $400 for horizontally fixing array, and extra charges for meter box upgrade, if applicable.
7. Delivery and Installation:
7.1. AS will make every reasonable effort to install your system in a timely manner. However, we will not be bound to meeting estimated or proposed delivery installation or system completion dates as we have no control over for example worldwide materials availability, peaks in demand created by changes in government legislation, inclement weather and/or other forms of force majeure. Delayed installation or grid connection is not a valid reason for claiming a refund on compensation from AS. Please note that no responsibility for the delay in installations is acceptable if customer details including installation site are incorrect.
7.2. Delays in installation are not grounds for cancellation and AS is not liable to you for any perceived loss because of these delays.
7.3. If difficulties with site access are encountered that were not notified to AS at the time of quote and/or offered by AS to the Customer, addition costs incurred in ensuring the safety of our installers may be payable by the Customer.
7.4. Before the installation can commence, and modifications to your roof take place you are required to arrange payment with the scheduling department for the balance payment of the system and that the goods remain the property of AS until your payment or finance payment, if applicable, is received.
7.5. A Home owner must be present during installation to sign the mandatory declaration assigning the STC’s to AS, as per the renewable Energy Act (2000) should the installer arrive on the agreed date and the home owner is not present, rescheduling fee of $220.00 will apply and the installation will be delayed.
7.6. If you have any preference regarding panel/inverter placement, you are required to inform the installer when they arrive on property.
7.7. If you have any present at the property during the time of installation, you are required to authorize an adult to be present at the property to sing all document and assume complete responsibility.
7.8. Upon signing the agreement, any requests for modifications to the material/equipment will incur an admin charge of $200. A new quote will be generated for any changes required.
8.1. You agree to provide AS with whatever personal information is required for the efficient functioning of AS on your behalf, in particular for the accurate completion of the paperwork for the STC’s incentive (selling the STCs) and network connection to the grid.
8.2. AS will provide your information to its contractors, employees and installers only as required to effectively perform their duties.
8.3. AS will provide your information, on your behalf to the relevant bodies for the processing the STC’s incentive (selling the STCs), to the electricity distributor for connecting your PV Solar system to the grid and if required to your electrician retailer.
8.4. Unless otherwise agreed with you, AS will not provide your personal information to any third parties other than those mentioned above.
8.5. You must sign all necessary documents on the date of installation for the performance of all party’s obligations under this arrestment.
8.6. AS will not sell your personal information under any circumstances.
9. Product Warranties:
The system comes with up to 10 years installation warranty from AS in conjunction with the manufacturer’s warranty. Without exception, when a balance remains unpaid to AS then all warranty callouts for maintenance, service and repairs remain suspended until the balance is received in full by AS. Furthermore, when a balance remains unpaid for more than 120 days, all warranty obligations by AS is terminated and callout for maintenance, service and repairs are chargeable to you. This provision does not negate the right for AS to claim the balance from you in a court or tribunal. AS does not provide any kind of warranties on the Monitoring system that comes with the inverter or on freebies or promo products.
10. Cooling off Period:
You understand that under Australian Consumer Law and relevant Sate Building Act you are entitled to a cooling-off period of ten (10) working days – where required. A notification must be received by AS in writing via email, fax or post.
Financing is not available on advertised specials. Terms and Condition of repayment of finance and interest will be provided by the Finance Company.
12.1. AS may terminate this contract with you if either of the following occurs.
12.1.1. You do not abide by the terms and conditions.
12.1.2. There are delays in the AS process causing supplier prices to increase in which case full deposit will be refunded.
12.1.3. AS has full authority to cancel the installation if installation cannot be possible. Customer will receive full refund of any deposit by cheque or other method.
12.1.4. You may terminate this agreement or contract within the first 10 days of quote date. You may be eligible to get a refund of deposit after deducting administrative charges. We normally procure the material or equipment within two weeks of receiving the signed copy of the contract. Customers would have to pay material cost if the job is cancelled after two weeks of receiving the signed copy of contract.